FIDIC 1999 vs 2017 Comparison PDF
Document Details
Uploaded by AstoundedHamster
null
Tags
Summary
This document compares the 1999 and 2017 versions of FIDIC contracts, highlighting changes to clauses related to definitions, Employer's financial arrangements, the role of the Engineer, and more.
Full Transcript
Sub-Clause 1.1: under Sub-Clause 1.1, the definitions now appear in alphabetical order and there are a number of new definitions to reflect FIDIC's core aim of increased clarity and certainty. For example: 'Claim', 'Date of Completion', 'Delay Damages', 'Dispute', 'Joint Venture', 'Notice', 'Notice...
Sub-Clause 1.1: under Sub-Clause 1.1, the definitions now appear in alphabetical order and there are a number of new definitions to reflect FIDIC's core aim of increased clarity and certainty. For example: 'Claim', 'Date of Completion', 'Delay Damages', 'Dispute', 'Joint Venture', 'Notice', 'Notice of Dissatisfaction' and 'Programme' are now defined terms, as are 'Extension of Time', 'Key Personnel', 'Noobjection' - the meanings of 'may', 'shall' and 'consent' have also been set out the 'Appendix to Tender' document under the 1999 FIDIC contracts, is now referred to as 'Contract Data' Particular Conditions' is now defined as comprising of two parts: Part A – Contract Data and Part B – Special Provisions. Abbreviations of some terms have also been added, for example: "DNP" for "Defects Notification Period", "EOT" for "Extension of Time", "IPC" for "Interim Payment Certificate", "FPC" for "Final Payment Certificate". The term "plus reasonable profit" as was used under the 1999 FIDIC contracts has been found to cause problems in practice and so a new definition "Cost Plus Profit" has been added in FlDIC's 2017 contract updates. This definition refers to a percentage for Contractor's profit to be stated in the Contract Data, but the default of 5% is stated in the event that nothing is stated in the Contract Data. Sub-Clause 1.3: the requirements under Sub-Clause 1.3 regarding Notices are now defined under SubClause 1.1. Sub-Clause 2.4: the provisions concerning the Employer's financial arrangements under Sub-Clause 2.4 have been further developed so that, in FIDIC's 2017 contract updates, the Employer is now required to describe such financial arrangements in the Contract Data, must notify the Contractor if there is a material change, and show (at the Contractor's request) that financial arrangements are in place for payment of Variations of value greater than the stated thresholds. Sub-Clause 3.1: under Sub-Clause 3.1 of the Red Book 2017, new specific provision has been made for what is commonly the case in practice, namely that 'the Engineer' appointed is a legal entity rather than an individual. Also, to reflect the fact that FIDIC is the global voice of the Consulting Engineering industry, there is a new requirement that 'the Engineer' is an engineering professional. In practice it is often the case that the Engineer is represented on site by a certain individual, and this is now reflected in a new sub-clause [Engineer's Representative]. This, and the following sections, have been modified to clarify, strengthen and reinforce the role of the Engineer to the contract. Sub-Clauses 3.4 & 3.5: in practice, the question of whether or not an instruction issued by the Engineer / Employer's Representative constitutes a Variation has caused difficulties. So, under what is now SubClause 3.5 in the Red Book 2017, if an instruction does not state that it is a Variation, the Contractor can give a Notice if he believes that it is a Variation, and the Engineer has the opportunity to confirm, reverse or vary the instruction within a stated time period. If this time period is not met, the instruction is deemed to have been revoked. Sub-Clause 3.7 in the Red Book 2017: the Engineer's role in dealing with the Parties' claims, and with other matters under the contract, is set out in greater detail using a step-by-step procedure with time limits, under what is now Sub-Clause 3.7 (Sub-Clause 3.5 under the 1999 Red Book):consultation with the Parties to encourage them to reach agreement → determination in the absence of agreement → effect of the agreement or determination → dissatisfaction with the determination. In order to promote what is expected of the Engineer under this Sub-Clause, namely that he deals with the Parties even-handedly in trying to broker an agreement between the Parties and, if there is no agreement in coming to a "fair determination" of the matter or claim, it is now expressly stated that what was implied under the 1999 Red Book: the Engineer is required to "act neutrally between the Parties" and "not be deemed to act for the Employer". To avoid the problems that many users have faced in recent years, it is now also expressly stated (under Sub-Clause 3.2) that there shall be no requirement for the Engineer to obtain the Employer's consent before exercising his authority under Sub-Clause 3.7. The provisions for agreement / determination, under Sub-Clause 3.7 of the Red Book 2017, now apply not just to claims but also: • • • • • • • • to measurement of the Works in the event that the Contractor does not agree with the Engineer's measurement - under Sub-Clause 12.1 [Works to be Measured] to a new rate / price in the event that the Contractor and the Engineer cannot agree the new rate/price - under Sub-Clause 12.3 [Valuation of the Works] to Variations: the Contractor's entitlement to extension of time and/or adjustments of the Contract Price/Schedule of Payments, under Sub-Clause 13.3 [Variation Procedure] where Daywork resources are not agreed, under Sub-Clause 13.4 [Daywork] where actual progress differs from planned progress affecting payment in accordance with a Schedule of Payments, under Sub-Clause 14.4 [Schedule of Payments] to the amount to be paid to the Contractor in respect of plant and/or materials when shipped or delivered to site, under Sub-Clause 14.5 [Plant and Materials intended for the Works] where the Engineer does not certify an amount that the Contractor considers should have been certified in a previous interim payment certificate, under Sub-Clause 14.6 [Issue of IPC] where the cause of a defect is in question, under Sub-Clause 11.2 [Cost of Remedying Defects]. Sub-Clause 4.2: Under Sub-Clause 4.2, the provisions relating to the Performance Security have been restructured, and there is now a new provision allowing for an increase or decrease of the amount of the security in the event that Variations result in an increase or decrease of the Contract Price above a stated threshold. There is also new wording stating that any amount that the Employer receives by claiming under the Performance Security is to be taken into account in the final payment certificate or, in the case of termination, in the valuation of payment due after termination. Sub-Clause 4.12: In the Red Book 2017, the provisions under Sub-Clause 4.12 [Unforeseeable Physical Conditions] have been restructured and further detail added in a step-by-step format so that it is clear what is expected, and when it is expected, of the Contractor and the Engineer in the event that unforeseeable conditions are encountered - notice by the Contractor - inspection and investigation by the Engineer - instruction by the Engineer - the Contractor's right to claim for any delay and cost – agreement / determination of the claimed delay and cost. Clause 5 of in the Red Book 2017 is now devoted to subcontracting (concerning ordinary subcontractors, as well as nominated subcontractors) and so, what was covered by Sub-Clause 4.4 and 4.5 in the Red Book 1999, have been moved to Clause 5. Sub-Clause 4.4 of the Red Book 2017 now provides for the situation where an element of the Works is to be designed by the Contractor and so this sub-clause sets out provisions concerning submission and review of the Contractor's design (and, where required under the Specification, as-built records and/or operation and maintenance manuals). Sub-Clause 4.5 of the Red Book 2017 deals with training by the Contractor of the Employer's personnel where such training is required under the Specification. A new sub-clause has been added under FIDIC's 2017 contract updates to provide for positions of Key Personnel to be identified by the Employer in the Specification (under the Red Book 2017) or the Employer's Requirements (under the Yellow and Silver Books 2017), for the persons named in the Contractor's tender to be appointed in those positions, and sets out the requirements if the Contractor wishes to replace any such person. Sub-Clause 5.1 & 5.2: contain a new provision for possibly limiting the value of subcontracted work for a particular contract by providing for this in the Contract Data (if nothing is stated in the Contract Data, the default maximum limit stated in this Sub-Clause is "the whole of the Works") - this appears under Sub-Clause 5.1 of the Red Book 2017. Also, the provisions relating to nominated subcontractors (SubClause 5.2 of the Red Book 2017) have been restructured and further details have been added in respect of the Contractor's right to object, and the payments to be made to nominated subcontractors. Sub-Clause 8.3: The Contractor's programme for execution of the Works is an important project management tool during the performance of the Works, and so Sub-Clause 8.3 has been updated with additional requirements for the initial programme and all revised programmes to be submitted to the Engineer for review. These additional requirements include: showing the Commencement Date, the Time for Completion of the Works and of any Section; the date or dates that the Contractor requires access to the Site or parts of the Site; the critical path and any float for logically linked activities; days of rest and holidays; key delivery dates for plant and materials; and in revised programmes, the actual progress to date, any delays and the sequence and timing of remedial works. The Contractor is also now required to include in the supporting report for each submitted programme the proposals to overcome the effects of any delay(s) to progress of the Works. The Engineer then has a stated time period for reviewing each submitted programme within which he/she can give a Notice stating that the programme is non-compliant with the Contract or the Contractor's obligations, or does not reflect actual progress - in which case the Contractor is required to submit a revised programme. If such Notice is not given within the stated time period, then a Notice of No-objection is deemed to have been given, and the submitted programme then becomes the Programme - which shall be followed by the Contractor and on which the Employer's personnel can rely. Sub-Clause 8.4: Under Sub-Clause 8.4 [Extension of Time for Completion] it is now expressly stated that there is no requirement for the Contractor to follow the claims procedure in respect of the entitlement to extension of time for Variations (please see further below). In the Red Book 2017, under sub-paragraph 8.4(c), the meaning of "exceptionally adverse climatic conditions" has been added, which it is hoped will avoid some of the difficulties that have arisen with the interpretation of this wording under the 1999 Red Book. The issue, which very often arises in practice, of concurrent Employer-delay and Contractor-delay has been addressed in a new paragraph under Sub-Clause 8.4. FIDIC has not set a mechanism for assessing the extension of time in such circumstances, but allows the Parties to include such a mechanism in the Special Provisions and gives guidance in the Notes for the preparation of Special Provisions, published with each of FIDIC's 2017 contract updates. Sub-Clause 9.1: Regarding Tests on Completion, Sub-Clause 9.1 has been improved by requiring the Contractor to submit a detailed test programme to the Engineer (under the Red Book 2017) and, when the Contractor considers that the tests have been successfully passed, to submit a certified report of the results of the tests. In each case, the Engineer or the Employer may then review what has been submitted and notify the Contractor of any non-compliance with the requirements of the Contract. Sub-Clause 10.1: Under Sub-Clause 10.1 [Taking Over of the Works and Sections], where the Contractor is required to submit as-built records and/or operation and maintenance manuals and/or to carry out training of the Employer's personnel (only if expressly stated in the Specification) the Works will not be ready for taking-over by the Employer until a Notice of No-objection has been given or deemed to have been given in respect of the records and/or manuals, and/or the training has been carried out. Sub-Clause 11.5, 11.6, 11.7: Where the Contractor requests consent to remove an item of Plant off-site for remedying defects, under Sub-Clause 11.5 there is a new requirement for the Contractor to give a Notice setting out the details of the item of Plant, the defect, transportation and insurance, and planned durations for the remedial works and re-installation. The provisions of Sub-Clause 11.6 [Further Tests after Remedying Defects] have been supplemented by requiring the Contractor to submit a proposal for repeat testing to the Engineer (under the Red Book 2017), who is then required to give a Notice agreeing to the Contractor's proposal or instructing the repeat testing that is required. The requirements under Sub-Clause 11.7 [Right of Access after Taking Over] have been developed by requiring the Contractor to give a Notice with details of what and when the access is required, and requiring the Employer to respond within a stated time period. If such access is unreasonably delayed, the Contractor has a new right to claim under this Sub-Clause. Clause 12, 12.1, 12.3: Measurement and evaluation of the Works under the Red Book 2017 remains under Clause 12. As noted above, there are new provisions under Sub-Clause 12.1 [Works to be Measured] and Sub-Clause 12.3 [Valuation of the Works] which require the Parties to proceed under Sub-Clause 3.7 [Agreement or Determination] if the Contractor and the Engineer cannot agree to the measurement of the Works or a new rate/price to be used to value the Works. Sub-Clause 13.1, 13.2: Under Sub-Clause 13.1 [Right to Vary] what was a ban on instructing an omission of any work to be carried out by others in the 1999 FIDIC contracts, is now qualified by allowing the Parties to agree to such a Variation - to deal with omissions of this type that do sometimes happen and have caused problems in practice. This new qualification is counter-balanced by a corresponding new provision under what is now Sub-Clause 13.3.1 [ Variation by Instruction] stating that, where the Parties agree to the omission, the Contractor will be entitled to recover loss of profit and other losses/damages (which is now excluded from the general statement of the Parties' non-liability for indirect losses / damages under the first paragraph of Sub-Clause 1.15 [Limitation of Liability]). Also under Sub-Clause 13.1, new grounds have been added to the Contractor's right to object to an instructed Variation: the varied work was Unforeseeable; that it will have an adverse effect on the Contractor's ability to comply with his/her health and safety and/or environmental obligations; In order to give the Parties full flexibility as to how the benefits / costs / delay of a Contractor's value engineering proposal under Sub-Clause 13.2 should be shared between the Parties, the wording has been amended to refer to details which can now be agreed between the Parties under the Particular Conditions. Sub-Clause 13.3: Sub-Clause 13.3 [Variation Procedure] has been restructured into two parts: SubClause 13.3.1 [Variation by Instruction] and Sub-Clause 13.3.2 [Variation by Request for Proposal]. If the Contractor has been requested to provide a proposal for a Variation, but the Variation is not then instructed, there is a new right for the Contractor to claim the cost of preparing the proposal. It is worth noting that, under a number of sub-clauses, there are now new provisions requiring the Variation procedure of Sub-Clause 13.3 to be followed. For example: - - - Sub-Clause 4.7.3 [Agreement or Determination of rectification measures, delay and/or Cost] of the Red Book 2017, for the measures to be taken by the Contractor to correct an error in the items of reference provided by the Employer Sub-Clause 8.7 [Rate of Progress] of Red Book 2017, in respect of any Engineer's instruction to revise the method of working or accelerate progress to reduce delays caused by matters for which the Contractor would be entitled to an extension of time Sub-Clause 13.6 [Adjustments for Changes in Laws] Red Book 2017, in respect of any necessary changes to the Works arising from changes in Laws Sub-Clause 17.2 [Liability for Care of the Works] Red Book 2017, for the Contractor's rectification of loss/damage resulting from any of the causes listed in this subclause. Sub-Clause 13.6: Under Sub-Clause 13.6 [Adjustments for Changes in Laws] the Contractor now has added entitlement to claim in the event of changes to permits / permissions / licenses/ approvals obtained for the Works, or to the requirements for the Contractor to obtain permits / permissions / licenses / approvals. Also added is an element of reciprocity between the Parties: the Employer can now claim a reduction in the Contract Price if a change in Laws gives rise to reduced costs for the Contractor. Sub-Clause 13.8: The somewhat complex formula that appeared under Sub-Clause 13.8 [Adjustments for Changes in Cost] of the Red Book 1999, has now been replaced in all three of FIDIC's contract updates 2017 by a reference to a "Schedule of cost indexation" in the Contract - in order to give the Parties full flexibility to agree to the method of calculating the adjustment to the Contract Price arising from changes in labor/plant/materials. If no such Schedule is included in the Contract, it is now stated that this Sub-Clause 13.8 does not apply. Sub-Clause 14.2: Sub-Clause 14.2 [Advance Payment] has been restructured and further detail added in a step-by-step format so that it is clear what is expected, and when it is expected, of the Contractor, the Employer (and the Engineer) in respect of the advance payment guarantee, making the advance payment, and repaying the advance payment. Sub-Clause 14.6: Similarly, for interim payments to the Contractor, Sub-Clause 14.6 has been restructured and further detail added in a step-by-step format so that it is clear what is expected, and when it is expected, of the Contractor, the Employer and the Engineer. As an addition to the requirement for the Contractor to provide the Performance Security, it is now stated that no interim payment amount is to be paid to the Contractor until the Contractor's Representative has been appointed. The Engineer is now required to "fairly consider" the amount of interim payment due to the Contractor and to identify any difference in any amount between what is certified / notified and what the Contractor included in his/her Statement giving reasons for the difference. There is now an added entitlement for the Engineer to take account of any error/discrepancy in a Statement until it is corrected by the Contractor in a subsequent Statement. Sub-Clause 14.7: Under Sub-Clause 14.7 [Payment], in order to give the Parties full flexibility to agree to the timing of payments, the time periods can be stated in the Contract Data (although this sub-clause also states default time periods in the event that none are stated in the Contract Data). Sub-Clause 14.11, 14.13: Sub-clause 14.11 [Final Statement] has been restructured and the wording has been amended to clarify the steps to be followed in respect of the draft Final Statement to be submitted by the Contractor leading to an agreed Final Statement or Partially Agreed Final Statement. Clause 15, Sub-Clause 15.6, Sub-Clause 15.7: The provisions under Clause 15 [Termination by Employer] have been restructured and further detail added in a step-by-step format to make it very clear what steps are to be followed before the Contract is terminated by the Employer: the Contractor's default/failure →Notice to correct → the Contractor's default/failure -→ Employer's Notice of intention to terminate (not required in the event of bankruptcy/insolvency or corruption/fraud on the part of the Contractor, the Contract can be terminated immediately) → the Contractor's further default/failure → Employer's Notice of termination → immediate termination. New rights of termination have been added – one example is where the Contractor's failure to comply with a binding determination or decision by the Dispute Avoidance / Adjudication Board (DAAB) constitutes a material breach of the Contract; another example is if the Contractor is in delay to such an extent that the Employer's entitlement to delay damages exceeds the maximum amount stated in the Contract Data. To clarify and add certainty in the situation where the Employer terminates the Contract for convenience, two new sub-clauses have been added: Sub-Clause 15.6 [Valuation after Termination for Employer's Convenience] and Sub-Clause 15.7 [Valuation after Termination for Employer's Convenience]. Clause 16: The termination provisions under Clause 16 [Suspension and Termination by Contractor] have similarly been restructured setting out steps to be followed before the Contract is terminated by the Contractor: the Employer's default/failure → Contractor's Notice of intention to terminate (not required in the event of bankruptcy / insolvency or corruption / fraud on the part of the Employer, the Contract can be terminated immediately) → the Employer's further default / failure → Contractor's Notice of termination - immediate termination. New rights of termination have been added - one example is where the Contractor does not receive a Notice of the Commencement Date within a stated time period, another example is where Employer's failure to comply with a binding determination or DAAB decision constitutes a material breach of the Contract. Clause 17: the heading has been changed to "Care of the Works and Indemnities", the sub-clauses have been re-ordered and the provisions have been clarified to more accurately reflect FIDIC's intention for the provisions of this clause and to avoid some of the difficulties experienced by users in practice in respect of what was Sub-Clause 17.3 [Employer's Risks] and Sub-Clause 17.4 [Consequences of Employer's Risks] in the 1999 FIDIC contracts. Sub-Clause 17.1, [Responsibility for Care of the Works] now deals with the Contractor's responsibility for care of the works and Sub-Clause 17.2 [Liability for Care of the Works] covers when and where the Contractor is liable and not liable for any loss/damage caused to the Works. Sub-Clause 17.3 now concerns intellectual and industrial property rights and, what was Sub-Clause 17.1 [Indemnities] in the 1999 FIDIC contracts, has now been split into Sub-Clause 17.4 [Indemnities by Contractor] and Sub-Clause 17.5 [Indemnities by Employer]. There is also a new sub-clause: Sub-Clause 17.6 [Shared Indemnities] - as mentioned above, the limitation of liability provisions under what was Sub-Clause 17.6 in the 1999 FlDIC contracts have been moved to a new sub-clause under Clause 1 in FlDIC's 2017 contract updates. Clause 18 [Exceptional Events] in FIDIC's 2017 contract updates now covers the subject-matter that was covered by Clause 19 [Force Majeure] in the Fl DIC 1999 contracts - the change in terminology from "force majeure" to "Exceptional Event” (now a defined term) being in line with the development introduced under FIDIC's Conditions of Contract for Design, Build and Operate Projects, first edition 2008 ('Gold Book'). Clause 19: in FIDIC's 2017 contract updates now covers insurance, and the provisions have been amended to align with similar provisions under Clause 19 of FIDIC's Gold Book (except Sub-Clause 19.3). Clause 20: The provisions of Clause 20 in FlDIC's 2017 contract updates concern only claims – as noted above; disputes are now dealt with under new Clause 21. Also as noted above, Contractor's claims and Employer's claims are now dealt with in exactly the same way. Sub-Clause 20.1 describes how a Claim (now a defined term) can be for time and/or money but also for a relief or remedy that is not time or money. For example: a request by the Contractor for the Employer to provide assistance under Sub-Clause 2.2 [Assistance]. The last paragraph of Sub-Clause 20.1 describes the procedure to be followed for claims that are not for time and/or money, and it is Sub-Clause 20.2 that deals with claims for time and/or money. Sub-Clause 20.2: [Claims for Payment and/or EOT] prescribes the step-by-step procedure to be followed for Employer's and Contractor's claims for time and/or money:- Notice of Claim (the 28 days’ time-bar provision of the 1999 FIDIC Contracts has been retained to apply to both Contractor's and Employer's claims) - the Engineer's initial response as regards the timing of the Notice of Claim → requirement to keep "contemporary records" (now defined under this Sub-Clause) → submission of the "fully detailed Claim" (also now defined under this Sub-Clause) and claims of continuing effect → agreement or determination of the Claim (by reference to Sub-Clause 3.7) The 28 days’ time-bar provision of the 1999 FIDIC Contracts has been the subject of much discussion and debate over the past number of years. In order to address some of the main difficulties, there are new provisions to deal with the situation where the Engineer's initial response is that the Notice of Claim is time-barred but the claiming Party disagrees or he/she believes there are circumstances justifying the late notice. In this case: - the claiming Party is required to include these points in the fully detailed claim, and the Engineer is required to proceed with agreement / determination of the Claim, taking into account the points raised by the claiming Party. It is recognized that these new provisions are a departure from what is stated under Sub-Clause 20.1 (a) in FIDIC's Gold Book 2008 which allows the DAB to consider the Contractor's justification for late submission of the Notice of claim and, if fair and reasonable, to overrule the time-bar. For the 2017 FIDIC contract updates, FIDIC came to the conclusion that it was more appropriate that the claiming Party's arguments concerning the timing of his/her Notice of Claim should first be considered during the agreement/determination process for the Claim. Then, if either Party is dissatisfied with the Engineer's (under Red and Yellow Books 2017) or the Employer's Representative's (under the Silver Book) determination, the issue can be referred to the DAAB for a decision. Clause 21: The provisions of new Clause 21 [Disputes and Arbitration] are, in essence, based on those set out in Sub-Clauses 20.2 to 20.8 of the 1999 FIDIC Contract, which have been further developed as summarized below. On the basis of how successful, in practice, 'standing' Dispute Adjudication Boards (as provided for under FIDIC's Red Book 1999), under Sub-Clause 21 [Constitution of the DAAB] in all the 2017 FIDIC contract updates, the Dispute Avoidance / Adjudication Board (DAAB) is to be a 'standing' board: i.e. appointed at the start of the Contract and in place for the duration of the Contract to assist the Parties with any disagreement / issue that may arise and to resolve any and all Disputes. This is in contrast to an 'ad-hoc' DAB (as provided for under FIDIC's Yellow and Silver Books 1999), appointed only when a dispute arises and only for that particular dispute. Based on many users' experience and the significant advantages of dispute avoidance, consistency of decisions if there is more than one Dispute and the benefits of having the DAAB as part of the 'project team', as a matter of best practice, It has been proven all over the globe that the appointment of a 'standing DAB' leads to a significantly increased probability of a successful project. A very important factor in the success of the dispute avoidance/adjudication procedure is the Parties' confidence in the agreed individual(s) who will serve on the DAAB, and it is important that DAAB member(s) are not imposed by one Party on the other Party. As such, provision has now been made in Contract Data for each Party to name three potential DAAB Members ensuring that both Parties have equal opportunity to put forward (the same number of) names for potential DAAB Members. Sub-Clause 21.2 [Failure to Appoint DAAB Member(s)] applies if the Parties cannot agree on a DAAB member. Sub-Clause 21.1: It has been noticed that, unfortunately, it has not been uncommon for a reluctant party to try to obstruct the appointment of the dispute board by failing to agree member(s) or, having agreed a member, by failing to agree his/her fees or to sign the DAB agreement. To avoid such difficulties, Sub-Clause 21.1 allows for the appointing entity stated in the Contract Data (if nothing is stated, the President of FIDIC) to appoint the DAAB member(s), to set the fees, and a DAAB agreement will be deemed to have been signed with the Parties. As a further incentive for the Parties to cooperate with each other in the appointment of the DAAB, under Sub-Clause 21.6 [Arbitration] a new provision has been added in respect of any award costs: allowing the arbitral tribunal to take account of a Party's failure to cooperate in the appointment of the DAAB. Sub-Clause 21.3: To reinforce and enhance the DAAB's role in assisting the Parties with any disagreements / issues and so avoid them becoming Disputes, new Sub-Clause 21.3 [Avoidance of Disputes] has been added. This Sub-Clause allows the Parties to jointly refer an issue to the DAAB and for the DAAB to "provide assistance and / or informally discuss and attempt to resolve any issue or disagreement that may have arisen" with the Parties. Similarly, the General Conditions of the Dispute Avoidance / Adjudication Agreement and the DAAB Procedural Rules have been improved by including further express provisions in respect of the DAAB's role in assisting the Parties to avoid Disputes. Hence the re-naming of the board to Dispute Avoidance/Adjudication Board in the 2017 FIDIC contract updates. Sub-Clause 21.4: [Obtaining DAAB's Decision] prescribes the step-by-step procedure to be followed for Disputes: referral to the DAAB (within a stated time period of the NOD, if Sub-Clause 3.7 is applied to the subject matter of the Dispute) → the Parties' obligations after referral of the Dispute → the DAAB's decision → dissatisfaction with the DAAB's decision. Sub-Clause 21.7: [Failure to Comply with DAAB's Decision] is based on Sub-Clause 20.7 of the 1999 FIDIC contracts, together with appropriate amendments which follow the recommendations given in the FIDIC Guidance Memorandum to Users of the 1999 Conditions of Contract dated 1st April 2013.