Podcast
Questions and Answers
What aspect is most vital when including reference standard specifications?
What aspect is most vital when including reference standard specifications?
- Specifying installation methods
- Confirming compliance with local codes
- Detailing brand names (correct)
- Listing approved manufacturers
To which division do vending machines typically belong?
To which division do vending machines typically belong?
- Division 13
- Division 10
- Division 11
- specialties (correct)
In a construction project, which party is typically responsible for determining the monetary value of extra work that was ordered by the owner?
In a construction project, which party is typically responsible for determining the monetary value of extra work that was ordered by the owner?
- The Contractor based on market rates
- The Project Manager based on schedule
- The Owner based on budget constraints
- The Architect based on contract provisions (correct)
What is the most vital aspect of maintaining temporary sanitary facilities on a construction site?
What is the most vital aspect of maintaining temporary sanitary facilities on a construction site?
What is a salient disadvantage associated with using performance specifications in construction projects?
What is a salient disadvantage associated with using performance specifications in construction projects?
Which of the following is NOT typically a step in preparing descriptive specifications for a construction project?
Which of the following is NOT typically a step in preparing descriptive specifications for a construction project?
What is a known disadvantage of using descriptive specifications?
What is a known disadvantage of using descriptive specifications?
Dumbwaiters, which are used to transport food, parcels and small goods across floors, typically belong to which construction division?
Dumbwaiters, which are used to transport food, parcels and small goods across floors, typically belong to which construction division?
For a modest 20-seater coffee shop interior, which division's products would LEAST likely be involved?
For a modest 20-seater coffee shop interior, which division's products would LEAST likely be involved?
What purpose does maintaining consistent terminology serve in construction specifications?
What purpose does maintaining consistent terminology serve in construction specifications?
What must a Contractor provide for fire protection on the premises?
What must a Contractor provide for fire protection on the premises?
What is the primary aim when using reference standard specifications?
What is the primary aim when using reference standard specifications?
What is the key role of a Surety in a construction contract?
What is the key role of a Surety in a construction contract?
Under which division does surveying for a construction project fall, given its focus on determining the positions, distances, and angles of points on the earth?
Under which division does surveying for a construction project fall, given its focus on determining the positions, distances, and angles of points on the earth?
When writing construction specifications, what is the recommended tone for phrasing?
When writing construction specifications, what is the recommended tone for phrasing?
A client is renovating a two-story villa and expanding the master bathroom. Which division would NOT likely be involved?
A client is renovating a two-story villa and expanding the master bathroom. Which division would NOT likely be involved?
When referencing external standards in construction specifications, which method is generally preferred?
When referencing external standards in construction specifications, which method is generally preferred?
Which of the following items would NOT typically be included in a list of bathroom fixtures?
Which of the following items would NOT typically be included in a list of bathroom fixtures?
In an emergency threatening life or property, what must the Contractor do?
In an emergency threatening life or property, what must the Contractor do?
In what way does a specification help in saving time and money on a project?
In what way does a specification help in saving time and money on a project?
Why is feedback from stakeholders recommended during the specification process?
Why is feedback from stakeholders recommended during the specification process?
Reference standard specifications primarily depend on what?
Reference standard specifications primarily depend on what?
Which of the following provides the best example of a performance specification?
Which of the following provides the best example of a performance specification?
What is the likely outcome if the Contractor fails to notify the Architect of Owner-caused project delays?
What is the likely outcome if the Contractor fails to notify the Architect of Owner-caused project delays?
If damages occur to adjacent property due to construction negligence, who is typically held liable?
If damages occur to adjacent property due to construction negligence, who is typically held liable?
Why should specifications avoid the use of legal jargon?
Why should specifications avoid the use of legal jargon?
In case of discrepancies between the drawings and the actual site conditions encountered during construction, which action ensures compliance?
In case of discrepancies between the drawings and the actual site conditions encountered during construction, which action ensures compliance?
In 2004, MasterFormat expanded to 50 divisions; under which subgroup were electrical products moved?
In 2004, MasterFormat expanded to 50 divisions; under which subgroup were electrical products moved?
Why is a specification considered a living document?
Why is a specification considered a living document?
What is NOT a requirement for temporary enclosures on a construction site?
What is NOT a requirement for temporary enclosures on a construction site?
What action must be taken regarding temporary structures erected by the Contractor after project completion?
What action must be taken regarding temporary structures erected by the Contractor after project completion?
What is the penalty for work identified as defective during the final acceptance phase of a construction project?
What is the penalty for work identified as defective during the final acceptance phase of a construction project?
What is the typical protocol when the Architect deems a worker to be inefficient?
What is the typical protocol when the Architect deems a worker to be inefficient?
In proprietary specifications, what differentiates closed specifications from open ones?
In proprietary specifications, what differentiates closed specifications from open ones?
Which of the materials listed does NOT belong to Division 4 (Masonry)?
Which of the materials listed does NOT belong to Division 4 (Masonry)?
Which option highlights a key benefit of using specifications in construction?
Which option highlights a key benefit of using specifications in construction?
In a typical project workflow, who generally provides the final certification prior to payment?
In a typical project workflow, who generally provides the final certification prior to payment?
A hospital bed typically belongs listed under which MasterFormat division?
A hospital bed typically belongs listed under which MasterFormat division?
How should the Contractor handle vegetation on the construction site during construction activities?
How should the Contractor handle vegetation on the construction site during construction activities?
Flashcards
Detailing Brand Names
Detailing Brand Names
Specifications should detail specific brands when incorporating reference standards.
Vending Machine Division
Vending Machine Division
Vending machines fall under Division 11.
Extra Work Valuation
Extra Work Valuation
The architect determines the value of extra work ordered by the owner based on contract provisions.
Sanitary Facilities
Sanitary Facilities
Signup and view all the flashcards
Performance Specs' Drawback
Performance Specs' Drawback
Signup and view all the flashcards
Descriptive Specs' Steps
Descriptive Specs' Steps
Signup and view all the flashcards
Descriptive Specs' Disadvantage
Descriptive Specs' Disadvantage
Signup and view all the flashcards
Dumbwaiter Division
Dumbwaiter Division
Signup and view all the flashcards
Coffee Shop Fit-Out
Coffee Shop Fit-Out
Signup and view all the flashcards
Spec Terminology
Spec Terminology
Signup and view all the flashcards
Fire Protection
Fire Protection
Signup and view all the flashcards
Reference Standards' Focus
Reference Standards' Focus
Signup and view all the flashcards
Surety's Role
Surety's Role
Signup and view all the flashcards
Surveying Division
Surveying Division
Signup and view all the flashcards
Spec Phrasing
Spec Phrasing
Signup and view all the flashcards
Bathroom Renovation
Bathroom Renovation
Signup and view all the flashcards
Specs' External Standards
Specs' External Standards
Signup and view all the flashcards
Typical lavatory
Typical lavatory
Signup and view all the flashcards
Emergency Response
Emergency Response
Signup and view all the flashcards
Specification Benefits
Specification Benefits
Signup and view all the flashcards
Stakeholder Feedback
Stakeholder Feedback
Signup and view all the flashcards
Reference Standards
Reference Standards
Signup and view all the flashcards
Performance Specs
Performance Specs
Signup and view all the flashcards
Delay Notification Failure
Delay Notification Failure
Signup and view all the flashcards
Negligence Liability
Negligence Liability
Signup and view all the flashcards
Avoid Legal Jargon
Avoid Legal Jargon
Signup and view all the flashcards
Discrepancy Resolution
Discrepancy Resolution
Signup and view all the flashcards
MasterFormat Expansion
MasterFormat Expansion
Signup and view all the flashcards
Specification Life
Specification Life
Signup and view all the flashcards
Temporary Enclosures
Temporary Enclosures
Signup and view all the flashcards
Contractor is responsible for doing this?
Contractor is responsible for doing this?
Signup and view all the flashcards
Defective Work Penalty
Defective Work Penalty
Signup and view all the flashcards
Protocol for Inefficient Worker
Protocol for Inefficient Worker
Signup and view all the flashcards
Study Notes
-
Detailing brand names is essential for properly incorporating reference standard specifications.
-
Vending machines belong to the specialties division.
-
The Architect determines the value of extra work ordered by the Owner based on contract provisions.
-
Contractors must maintain temporary sanitary facilities to ensure they are ample, clean, and kept orderly.
-
Enforcing compliance is more challenging than other methods in the context of disadvantages of performance specifications.
-
Establishing recognized benchmarks does NOT describe a step in preparing descriptive specifications.
-
Descriptive specifications can become wordy and lengthy.
-
Dumbwaiters, used to transport food and other small items, belong to Division 14.
-
Materials needed for a modest 20-seater coffee shop are LEAST likely to involve products from Division 14.
-
Maintaining consistent terminology in specifications ensures clarity.
-
Contractors must provide water barrels and fire buckets for fire protection on the premises.
-
Establishing recognized benchmarks is the primary focus of reference standard specifications.
-
The Surety's role in a contract is to provide a bond guarantee.
-
Surveying falls under the Existing Conditions division.
-
The recommended tone for phrasing specifications is the imperative mood.
-
Specifications for renovating a foreclosed two-story villa's master bedroom would involve several divisions, EXCEPT none of the other choices.
-
Summarizing their content is the preferred method for referring to external standards or codes in specifications.
-
Bidet, pedestal lavatory, shower fixture set, and one-piece water closet belong to the list, EXCEPT the shower cubicle enclosure
-
In emergencies threatening life or property, Contractors must act at their discretion to prevent loss.
-
Specifications save time and money by including specific materials and instructions, and giving directions to the project.
-
Stakeholder feedback is recommended to enhance the document's clarity and completeness.
-
Recognised authoritative standards are what reference standard specifications primarily rely on.
-
A solar panel generating 500 watts with 21% efficiency is an example of performance specifications.
-
If the Contractor fails to notify the Architect of delays caused by the Owner, arbitration will settle disputes without penalties.
-
The Contractor is liable for damages to adjacent property due to construction negligence.
-
Legalese and Jargon should be avoided in specifications to enhance clarity for readers.
-
In discrepancies between actual site conditions and drawings, the action that ensures compliance is the Contractor modifying the design.
-
When MasterFormat expanded from 16 to 50 divisions in 2004, Electrical products moved to the Facilities Services subgroup.
-
A specification is considered a living document to be used throughout construction and not stop after the design phase.
-
Resistance to fire is NOT a requirement for temporary enclosures.
-
After project completion, the Contractor's temporary structures must be dismantled and removed by the Contractor
-
The penalty for defective work identified during final acceptance is rebuilding in accordance with specifications
-
If a worker is deemed inefficient by the Architect, the Contractor must replace the worker immediately.
-
In proprietary specifications, the primary difference between closed and open specifications is that closed specifications prohibit substitutions, while open ones allow them.
-
Materials belonging to Division 4 include everything EXCEPT stone anchors.
-
Specifications in construction provide answers to on-site construction questions.
-
The Architect issues the final certification before payment.
-
A hospital bed belongs to Division 10.
-
Contractors should box and protect existing vegetation to remain during construction.
-
Bulleted or numbered lists are recommended to present essential information in specifications.
-
Trash chutes, dumbwaiter, laundry & linen chutes, luggage carousel belong in the group, EXCEPT elevator
-
Three copies of shop drawings are initially submitted for approval.
-
Division 12 falls within the turf of architects.
-
Door hinges, barrel bolts, and door knobs belong to Division 8.
-
When drawings and specifications differ, and an expensive method is chosen without clarification, the Contractor is liable.
-
Reference Standard specification type primarily emphasizes industry-wide recognition and acceptance.
-
A specific brand is required and most applicable to proprietary specifications.
-
A Bid Bulletin is provided to clarify project details before bidding.
-
A characteristic advantage of performance specifications is that they promote contractor accountability for results.
-
Metal lockers belong to Division 10
-
Proprietary specifications enable detailed drawings based on specific information.
-
The Construction Specifications Institute (CSI) established in 1948 began to draft guidelines for specifications and was published in September of 1963.
-
A specification assists subsequent asset management during the soft landing process.
-
The Contractor verifies the equipment fits the available space before installation.
-
Proprietary specifications limit competition significantly.
-
The Contractor bears the expenses for temporary provision of water and power.
-
Seeking external contractors for work is what the owner can do if a major change is required, and no price agreement is reached.
-
Ensuring the standard is industry-acknowledged is critical in crafting reference standard specifications.
-
Specifying brand-specific details does NOT describe a step in preparing descriptive specifications.
-
HCG manufactures products belonging to Division 15.
-
Performance specification type allows the contractor to select the method of achieving specified results
-
Wood parquet tiles does not belong to the group
-
The 30s series (Division 30, 31, 32...) the 50 Divisions starting 2004, are relegated to the Site and Infrastructure group.
-
Weakness in structural parts during material trial usage by the Owner cannot be inferred.
-
The Contractor is accountable for securing permits before construction begins.
-
Logical numbering for clauses simplifies document modifications.
-
Fenestration, the arrangement and proportioning of openings in a surface/architecture, falls under Division 8.
-
Crushed stone aggregate with angular, well-graded particles is an example of a descriptive specification.
-
Descriptive specifications do NOT promote contractor flexibility in methods.
-
Performance specifications primarily focus on specifying desired outcomes
-
Specifications minimize project risk by being part of contractual documents
-
A junior architect tasked to look for eco-friendly wood composite partitioning in the shopping mall toilet should focus on Division 10.
-
Airtight windows are NOT included in Division 7 products.
-
Descriptive specifications do NOT require less time to create.
-
Temporary housing for workers are located in designated areas specified by the Architect.
-
Unnecessary alternatives should be avoided in specification text because they create ambiguity in instructions.
-
The Contractor should replace or rebuild defective work immediately upon discovery.
-
Typos and grammatical errors should be avoided in specifications because they can lead to misunderstandings.
-
Paints, Coatings, Tiling, Plasters, and Ceilings belong to Division 9.
-
Under Article 19.01, if a worker is deemed inefficient, the Architect can withhold payment to the Contractor.
-
Reference standard specifications benefit project documentation by reducing redundancy and conflict.
-
Plumbing fixtures from Delta, model "Linden" is an example of a proprietary specification.
-
Descriptive specifications describe materials and installation methods in detail, without specifying brand names.
-
Snow-making machine, dialysis machine, digital projector, tennis ball launcher do not belong to the group, EXCEPT cold storage facility
-
A main disadvantage of proprietary specifications is that they depend on minimum requirements.
-
Ensureing the asset delivered matches the client's commission is how specifications support the interpretation of the client brief.
-
A roofing underlayment conforming to ASTM D226 standards is a Reference Standard specification type.
-
Division 13 materials needed for constructing a cellphone repair shop, EXCEPT.
-
Minimizing redundancy in specifications avoids conflicting information.
-
A primary disadvantage of steel is its high susceptibility to corrosion.
-
Structural Steel is most commonly used for primary structural frameworks in buildings.
-
Integral waterproofing compounds like SAHARA primarily enhance water resistance for concrete.
-
Tool Steel is primarily alloyed with vanadium and tungsten to enhance its hardness and heat resistance.
-
Narra is a wood species suitable for coastal regions because it's resistant to decay and insect attack.
-
Umbrella nails were traditionally used to attach sheet metal roofing to wooden purlins.
-
Malleability allows steel to be rolled into sheets without fracturing.
-
High alkali resistance makes magnesium alloys suitable for formwork applications.
-
Tek screws are generally used for attaching sheet metal roofing to C-purlins.
-
Quarter-sawn lumber is preferred for flooring because its higher resistance to shrinkage and warping
-
Blockboard is is best to reduce the weight of a wooden panel while maintaining stability for wardrobe cabinetry.
-
Durability is most important for ensuring steel's long lifespan in structures.
-
Pre-painted steel over galvanized steel has improved aesthetic appeal and corrosion resistance
-
Cement-based waterproofing coatings must be protected with plaster or topping to enhance water resistance and durability.
-
Poor workmanship/improper concrete consolidation is the most likely cause of water seepage in a newly constructed swimming pool.
-
Hardboard is an engineered wood product made from compressed wood fibers and is denser than MDF.
-
Janka hardness rating should be prioritized for flooring that withstand constant impact.
-
Exterior cladding does NOT typically require waterproofing.
-
Unusually high moisture content in mahogany will result in decreased durability and increased plasticity
-
26 gauge is most commonly specified for galvanized iron (G.I.) roofing sheets
-
Wood expands and contracts with changes in humidity due to absorption and release of bound water in cell walls.
-
Applying an insulating layer is the best way to address the developer's concern about thermal conductivity of steel
-
Increased thermal insulation is the primary advantage of multi-wall polycarbonate roofing over twin-wall.
-
Epoxy-Coated Rebar is the type of rebar that is coated to resist corrosion in harsh environments.
-
Metal sheet is the type of under-sheathing is clay tiles are typically installed in the Philippines?
-
Clay roofing tiles provide the best long-term performance for a building in a high-humidity coastal environment.
-
Weathering Steel is designed to form a protective rust layer that inhibits further corrosion.
-
The price of thin, long cuts of wood is determined per lineal foot or lineal meter.
-
Increasing carbon content in carbon steel increases hardness but reduces ductility.
-
MDF with veneer overlay is used to produce affordable wooden panels that mimic the grain appearance of solid wood.
-
Wood species and density has the most significant effect on the Janka hardness rating of wood.
-
Brown rot is primarily caused by fungal activity in damp conditions.
-
Expansion and contraction is most crucial to account for in installation for polycarbonate roofing
-
Damp-proofing reduces the effect of capillary moisture movement from the ground and in walls, primarily
-
Board foot is the most common pricing unit for rough lumber.
-
Particleboard is the least resistant to moisture.
-
Tree species and board dimensions have the greatest impact on price of solid lumber.
-
Wood that returns to its original shape after bending displays high elasticity.
-
Use galvanized steel beams to prevent steel beams from rusting in an exposed coastal environment.
-
A thin piece of lumber with a thickness of less than 1 1/2" is known as a "board"
-
Chromium must be present in stainless steel to enhance its corrosion resistance.
-
The bituminous coating being incompatible with the foundation concrete is the likely design flaw for persistent water infiltration
-
Zinc is primarily used in galvanization to protect steel from corrosion
-
Roofing sheets are cut before installation to minimize horizontal joints and improve weather resistance.
-
To minimize horizontal joints to improve weather resistance
-
Honeycomb is most likely to develop in improperly seasoned wood stored in a humid environment.
-
Aluminum is a lightweight yet durable metal that's best suited for a high-rise building's cladding system.
-
Fireproofing structural steel components increases fire resistance rating.
-
Batt insulation is commonly used inside dry wall cavities.
-
A jib door has no visible hinges and blends with the wall surface.
-
A primary advantage of LVT over traditional vinyl sheet flooring is more realistic texture and appearance.
-
Acoustic insulation works to absorb and control sound transmission.
-
A door that is "invisible" is a type of hinge
-
Shatters harmless = tempered glass
-
Weatherstrip shown
-
The Gravity hinge shown
-
Informational kiosks commonly include interactive touchscreens.
-
Cement plaster is generally preferred for exterior applications rather than gypsum plaster.
-
Laminated glass provides both safety and security by using two or more layers.
-
Spandrel glass conceals structural elements in a façade.
-
The kind of flooring that is not resilient is laminate
-
Annealed glazing not a type of glazing method
-
Protective covers provide sun-shading and weather protection in exterior applications.
-
Hinge shown
-
The primary characteristic of a Dutch door is that it is divided horizontally into two independent operable sections.
-
Open-cell ceilings are specifically designed to create visually open yet structured spaces.
-
Acoustic gypsum board would be best suited where a large auditorium needs both impact resistance and superior acoustics.
-
The head of a wood door frame runs horizontally at the top.
-
Marble materials that are most susceptible to acid etching and efflorescence
-
Bumper guards are effective in preventing impact from carts and wheelchairs.
-
a hospital lockset is being referred to with the push plate and pull handle in the image
-
Demountable partitions are the most appropriate where an office space requires flexible partitions.
-
Cast Iron is least commonly used for constructing toilet compartments.
-
kick plate being shown
-
Exterior sun control devices provide passive daylight control while reducing heat gain.
-
Acrylic plaster is a decorative plaster finish that is flexible, easy to apply, and comes in pre-mixed colors.
-
The Romans pioneered the use of lime plaster for architectural applications
-
Integrated ceiling assembly integrates functions such as acoustics, lighting, and HVAC.
-
Panic hardware is used for emergency exit doors.
-
Revolving doors best suited for maximizing accessibility while maintainingenergy efficiency at entrances in high rise buildings
-
Difference between telescopic and bypass doors Bipass requires multiple tracks while telescopic stack panels
-
An advantage that acrylic plaster requires frequent recoating for durability
-
Purpose of patient bed service wall in healthsetting
-
House utilities such as O2, Power, medical gas outlets
-
Engineered wood flooring preferred over solid wood as it expands and contactls less
-
Jalousie style window has horizontal states that can be tilted to airflow
-
Ensure door closes automatically is the purpose of door closure
-
The gypsum board the lightweight fire resistant sound protection wall partition
-
Function of spectrum selective glass that filleting in solar heat allows maximunm natural light
-
Insulated glasas unit that consists of multi paned units that separted with air
-
Ceiling stem must meet stringent fire safety/ acoustic performance a linear perforated metal material is used
-
rubber flooring absorbs and relieves fatigue
-
Advantage of wire mesh partitions is they allow visibility and restrict access
-
substrate has to be clean so it prevents premature peeling / adhesion
-
a morrise lockset being referred to by door hardware
-
operable protions because they provide that sound control flexibility space
-
Half morrise hinge refers to b on the image
-
Mutton is primary structural component separates multiple window units?
-
Roll up doors commercial industrial for roll up abilities
-
A drywall frame is used for drywall construction
-
Cement is used for binding agent in concrete
-
masonary examples except none of the choices
-
Schedule 40' pipes example of discriptive specifications
-
construction because of all the following except none of the choices of that defind
-
M20 is the mix probably will provide 20 mpa after 28 days
-
A cement mis glue maronary united together mortar
-
A person rejection architect
-
specification provide clear enforceable requirements focus
-
borrowed soil that can be excavated
-
imperitive mood
-
Technical specific actions specific direction
-
Earth work activity
-
Specifications ensure accuracy in technical specifications
-
Division 14 Least likely in construction
-
Slump test access fresh concrete
-
Division 0 acquires services and products
-
Owner holds the power order the project execution
-
architect wants performance characteristics = performance specifications should be
-
survey techinque division existing conditions
-
standard typical block size 200mm x 400mm
-
1-3-6 ratio mixture concrete,
-
class C is classified
-
not a well written specification except redundancy and repetition is not a characteristic
-
Finishing, which means bricklayer
-
Electrical systems from format division assigned to 16
-
excavation below water leverls dredging
-
Division 7 products airtight windows
-
performance conform established standard
-
example reference specifications
-
Earthwork doesn't transport to site excavation
-
no the choices back filling
-
Anle of Repose the support level in groundwater
-
Concrete slows down the setting time in hot weathers by retarder
-
Beams mixture class A
-
NOT recommened legalise jargonising
-
running bond is the type of pattern A on image
-
class aa for retaining walsunderwater
-
specifaction
-
cement mix usues 9 units, class A
-
Facade outer Veneer Construction
-
mechanical energy compaction
-
specifications none of choices
-
A Stack Bond
-
The facilities srvies sub group Master
-
Standards minimizes redudancy through codes being used
-
bottom wall cavity construction
-
rewriting entirely
-
thick wall of earth embankment
-
brand specific
-
Masonry walls is a mortar set up
-
walls should have 3 meters
-
materials production wprmanship
-
refractory brick
-
excavation process
-
incorrect of hydration hardened
-
plant and critical class C
-
plumbing is under mechanicals
-
earthworks conditions investigations are done
-
cover defined
-
concrete 75mm
-
0.774 m3 is the volume of component
-
that you can reduce to 25cm x25cm to .488 M3
-
unnecassary sets savings is used up to 6.528 m3
-
the class B is below standards should be used
-
structural members = 53 bags needed
-
1500 difference
-
1333 unites of exterior walls
-
8.415 M3
-
82 Bags of walls
-
9 cubic wall of meter
-
walls of exterior 29 bags
-
plaster of exterioir 18 bags
-
purpose of the adding is all the choice
-
time is 14 days Footing is the ties
-
Engineer not used the prepared
-
A proposed party by the contractor
-
repose of angle 40 degree
-
class A concrete
-
specific material choose closed
-
oraginzatoon for readability
-
All material and expection buulk
-
All division EXCEPT DIVISION 13
Studying That Suits You
Use AI to generate personalized quizzes and flashcards to suit your learning preferences.